Overview
This section mandates that contracting officers must request a new wage determination via the e98 process if there is a delay of more than 60 days in bid opening or the start of work.
Key Rules
- Trigger: A delay of more than 60 days from the date originally indicated on an e98 for either bid opening (sealed bidding) or commencement of work (negotiated contracts).
- Action Required: The contracting officer must submit a new e98 request to the Department of Labor.
- Supersession: Any revised wage determination resulting from the new e98 replaces the previous determination.
- Timing Constraints: The application of the new wage determination is still subject to the specific effectiveness windows found in FAR 22.1012-1(b) and (c).
Practical Implications
- Contracting officers must monitor procurement timelines closely, as significant delays can lead to updated labor rates that may impact the total contract value or require budget adjustments.
- Offerors and contractors should be prepared for potential changes in minimum wage and fringe benefit requirements if a project's start date is pushed back significantly.